At www.interiorplus.in/, accessible from www.interiorplus.in/, one of our main priorities is the privacy of our visitors. This Privacy Policy page contains types of information that is collected and recorded by www.interiorplus.in/ and how we use it.
If you have additional questions or require more information about our Privacy Policy, do not hesitate to contact us – at [email protected]
Log Files
www.interiorplus.in/ follows a standard procedure of using log files. These files log visitors when they visit websites. All hosting companies do this and a part of hosting services’ analytics. The information collected by log files include internet protocol (IP) addresses, browser type, Internet Service Provider (ISP), date and time stamp, referring/exit pages, and possibly the number of clicks. These are not linked to any information that is personally identifiable. The purpose of the information is for analyzing trends, administering the site, tracking users’ movement on the website, and gathering demographic information.
Cookies and Web Beacons
Like any other website, www.interiorplus.in/ uses “cookies”. These cookies are used to store information including visitors’ preferences, and the pages on the website that the visitor accessed or visited. The information is used to optimize the users’ experience by customizing our web page content based on visitors’ browser type and/or other information.
Google DoubleClick DART Cookie
Google is one of a third-party vendor on our site. It also uses cookies, known as DART cookies, to serve ads to our site visitors based upon their visit to www.website.com and other sites on the internet. However, visitors may choose to decline the use of DART cookies by visiting the Google ad and content network Privacy Policy at the following URL – https://policies.google.com/technologies/ads
Privacy Policies
Third-party ad servers or ad networks uses technologies like cookies, JavaScript, or Web Beacons that are used in their respective advertisements and links that appear on www.interiorplus.in/, which are sent directly to users’ browser. They automatically receive your IP address when this occurs. These technologies are used to measure the effectiveness of their advertising campaigns and/or to personalize the advertising content that you see on websites that you visit.
Note that www.interiorplus.in/ has no access to or control over these cookies that are used by third-party advertisers that are not liked to Interior Plus in any way.
Third Party Privacy Policies
www.interiorplus.in/’s Privacy Policy does not apply to other advertisers or websites. Thus, we are advising you to consult the respective Privacy Policies of these third-party ad servers for more detailed information. It may include their practices and instructions about how to opt-out of certain options.
You can choose to disable cookies through your individual browser options. To know more detailed information about cookie management with specific web browsers, it can be found at the browsers’ respective websites. What Are Cookies?
Children’s Information
Another part of our priority is adding protection for children while using the internet. We do not collect information pertaining to any children.
www.interiorplus.in/ does not knowingly collect any Personal Identifiable Information from children under the age of 13. If you think that your child provided this kind of information on our website, we strongly encourage you to contact us immediately and we will do our best efforts to promptly remove such information from our records.
Online Privacy Policy Only
This Privacy Policy applies only to our online activities and is valid for visitors to our website with regards to the information that they shared and/or collect in www.interiorplus.in/. This policy is not applicable to any information collected offline or via channels other than this website.
Consent
By using our website, you hereby consent to our Privacy Policy and agree to its Terms and Conditions.
Works contract
Scope of services:
The scope of the services (“Services”) provided by INTERIOR PLUS are as follows:
a. Designing of home interiors or/and
b. Provision and supply of customized home furniture or/and
c. Installation of the customized home furniture at your site – apartment, villa, house etc. or/and
d. Facilitate delivery of select products and services by third-party partners, as part
of the overall interior design solution
Delivery guarantee
a. 45-Days Delivery Guarantee: The INTERIOR PLUS 45-Days Delivery Guarantee will be applicable only if all the conditions above (Clause 2) are met in full and Private and Confidential | Page 1 of 14 your overall scope of services contains only items from the categories mentioned in Annexure 2A.
b. Services & products with No Delivery Guarantee: If your order contains services
& products from the categories mentioned in Annexure 2B, which are
partner-managed, no delivery guarantee will apply for these specific items.
c. Conditions that will make the Delivery Guarantee for your entire order NULL & VOID: No Delivery Guarantee will be applicable for items/areas mentioned in Annexure 2C.
d. Only working days will be considered for the calculation of 45 days
Payment for services rendered
a. The total price payable by you for the Services (“Price”) shall be as per the quotation sent to you by INTERIOR PLUS and accepted by you.
b. The Price shall be payable as per the following milestones:
Milestone Amount Timeline
1st Milestone 10% (ten percent) of the Estimate Booking / confirmation of work order
2nd Milestone 60% (sixty percent) of the Price (minus the booking
amount) within 2 Working Days from the time of design finalization and prior to the commencement of manufacturing by INTERIOR PLUS
3rd Milestone 40% (forty percent) of the Price once materials are ready to deliver to site.
c. in case you instruct us to hold the material dispatch or do not accept the material dispatch within 15 days from the scheduled dispatch date / date on which the material is ready for dispatch, then risk associated with material shall be transferred to you from the 16th day and in such a case INTERIOR PLUS shall only hold the material on your behalf and shall levy a storage charge of Rs. 250 per day of delay.
d. INTERIOR PLUS shall not be liable for any damages, loss and theft of the material lying in the warehouse beyond 15 (fifteen) days from the scheduled dispatch date.
e. The Price is inclusive of all applicable duties and taxes.
f. All payments shall be made via cheque/demand draft/bank transfer (NEFT/RTGS) Only.
Refund policy
- Within 48 hours of booking (0 to 10%) – Design stage – 100% refund
- Post 48 hours of the project booked (10% to 60%) – Design stage – 0% refund
- After 60% payment – Product stage – 0% refund – The client is not eligible for any refund and will be obligated to pay the last payment of 40% payment in compliance with works contract.
Cancellation policy
a. However, INTERIOR PLUS may delay or cease to provide the Services in case the Price payable remains unpaid or is delayed; in which case, INTERIOR PLUS shall have no obligation to refund the amounts already paid by you.
b. After agreeing to these Terms and Conditions, in case you seek to not avail of the Services, you will forfeit all the amounts already paid by you to INTERIOR PLUS and also be liable to pay the balance of the Price agreed to be paid to INTERIOR PLUS, as due compensation for the losses that will be suffered by INTERIOR PLUS in such an eventuality and not as penalty.
Governing law & jurisdiction
a. The terms and conditions contained herein regarding the provision of Services, shall be governed and interpreted in accordance with the laws of India, and any dispute arising therefrom shall be submitted to the exclusive jurisdiction of the courts at Bangalore, India.